Last update: Apr 9, 2025
Terms & Conditions
1. Introduction
Welcome to Marvista Design Group. By accessing or using our website and services, you agree to comply with and be bound by these Terms & Conditions. If you do not agree, please refrain from using our website.
2. Services
We provide architectural and interior design services, including but not limited to design consultation, space planning, custom furniture, cabinetry, and bespoke rugs and carpets. All services are subject to separate agreements, proposals, or contracts.
3. Use of Website
You agree to use this website for lawful purposes only. You must not:
Use the website in any way that may damage or impair its performance
Attempt to gain unauthorized access to our systems
Copy, reproduce, or exploit any content without prior written consent
4. Intellectual Property
Unauthorized use, reproduction, or distribution of content on this website, including text, images, designs, drawings, logos, and graphics is strictly prohibited.
5. Project Engagement
Submitting an enquiry through our website or email does not constitute a binding agreement.
All projects will be governed by a formal contract outlining scope, timelines, deliverables, and payment terms.
6. Pricing & Payments
All fees, quotations, and estimates are subject to change based on project scope and requirements.
Payment terms will be clearly defined in individual project agreements. Delays in payment may result in delays or suspension of services.
7. Production, Delivery, and Installation
Production: The estimated production lead time is 4–14 weeks, depending on the type of order and material availability. This estimate covers manufacturing only. Allow additional time for shipping and delivery or for warehouse pickup.
Shipping and delivery: Our logistics partners handle shipping and delivery. Timing varies by destination and shipping method. For shipped orders, we will provide an estimated ship-by date or window before you place your order.
Warehouse pickup: If warehouse pickup is arranged, we will confirm separately when and where your order will be ready for collection.
Installation: When installation is included in your order, our installation partners carry out the work. Scheduling and duration vary by location and scope of work.
Schedule changes: Delivery and installation timelines are estimates and may change due to factors outside our reasonable control. we will notify you promptly and keep you informed about the revised schedule and your options.
8. Third-Party Vendors & Products
We may recommend or work with other third-party vendors, contractors, or suppliers. While we aim to collaborate with reliable partners, we are not responsible for:
Quality, delays, or defects from third-party services
Pricing changes or availability of third-party products
9. Limitation of Liability
To the fullest extent permitted by law, Marvista Design Group shall not be liable for:
Any indirect, incidental, or consequential damages
Loss of data, profits, or business opportunities
Delays or failures caused by factors beyond our control
All services are provided on an “as is” and “as available” basis.
10. Accuracy of Information
While we strive to ensure that all information on our website is accurate and up to date, we do not guarantee completeness or accuracy. Content may be updated or changed without prior notice.
11. Cancellation & Refunds
Cancellation and refund policies will be defined in individual project agreements.
Any deposits or payments made may be non-refundable unless otherwise stated.
12. Privacy
Your use of our website is also governed by our Privacy Policy. By using this website, you consent to the collection and use of your information as outlined there.
13. Governing Law
These Terms & Conditions shall be governed by and interpreted in accordance with the state laws. Any disputes shall be subject to the exclusive jurisdiction of the courts in that region.
14. Changes to Terms
We reserve the right to update or modify these Terms & Conditions. Continued use of the website constitutes acceptance of the revised terms.
15. Contact Information
For any questions regarding these Terms & Conditions, please contact us at:
Email: info@marvistadesigngroup.com
1. Introduction
Welcome to Marvista Design Group. By accessing or using our website and services, you agree to comply with and be bound by these Terms & Conditions. If you do not agree, please refrain from using our website.
2. Services
We provide architectural and interior design services, including but not limited to design consultation, space planning, custom furniture, cabinetry, and bespoke rugs and carpets. All services are subject to separate agreements, proposals, or contracts.
3. Use of Website
You agree to use this website for lawful purposes only. You must not:
Use the website in any way that may damage or impair its performance
Attempt to gain unauthorized access to our systems
Copy, reproduce, or exploit any content without prior written consent
4. Intellectual Property
Unauthorized use, reproduction, or distribution of content on this website, including text, images, designs, drawings, logos, and graphics is strictly prohibited.
5. Project Engagement
Submitting an enquiry through our website or email does not constitute a binding agreement.
All projects will be governed by a formal contract outlining scope, timelines, deliverables, and payment terms.
6. Pricing & Payments
All fees, quotations, and estimates are subject to change based on project scope and requirements.
Payment terms will be clearly defined in individual project agreements. Delays in payment may result in delays or suspension of services.
7. Production, Delivery, and Installation
Production: The estimated production lead time is 4–14 weeks, depending on the type of order and material availability. This estimate covers manufacturing only. Allow additional time for shipping and delivery or for warehouse pickup.
Shipping and delivery: Our logistics partners handle shipping and delivery. Timing varies by destination and shipping method. For shipped orders, we will provide an estimated ship-by date or window before you place your order.
Warehouse pickup: If warehouse pickup is arranged, we will confirm separately when and where your order will be ready for collection.
Installation: When installation is included in your order, our installation partners carry out the work. Scheduling and duration vary by location and scope of work.
Schedule changes: Delivery and installation timelines are estimates and may change due to factors outside our reasonable control. we will notify you promptly and keep you informed about the revised schedule and your options.
8. Third-Party Vendors & Products
We may recommend or work with other third-party vendors, contractors, or suppliers. While we aim to collaborate with reliable partners, we are not responsible for:
Quality, delays, or defects from third-party services
Pricing changes or availability of third-party products
9. Limitation of Liability
To the fullest extent permitted by law, Marvista Design Group shall not be liable for:
Any indirect, incidental, or consequential damages
Loss of data, profits, or business opportunities
Delays or failures caused by factors beyond our control
All services are provided on an “as is” and “as available” basis.
10. Accuracy of Information
While we strive to ensure that all information on our website is accurate and up to date, we do not guarantee completeness or accuracy. Content may be updated or changed without prior notice.
11. Cancellation & Refunds
Cancellation and refund policies will be defined in individual project agreements.
Any deposits or payments made may be non-refundable unless otherwise stated.
12. Privacy
Your use of our website is also governed by our Privacy Policy. By using this website, you consent to the collection and use of your information as outlined there.
13. Governing Law
These Terms & Conditions shall be governed by and interpreted in accordance with the state laws. Any disputes shall be subject to the exclusive jurisdiction of the courts in that region.
14. Changes to Terms
We reserve the right to update or modify these Terms & Conditions. Continued use of the website constitutes acceptance of the revised terms.
15. Contact Information
For any questions regarding these Terms & Conditions, please contact us at:
Email: info@marvistadesigngroup.com